Public Offer Agreement for Software Development Services

Effective Date: December 20, 2025

IP Bunkov Maksim Vladislavovich (hereinafter referred to as the "Contractor") hereby offers any individual or legal entity (hereinafter referred to as the "Client") to enter into an agreement for software development services on the terms and conditions set forth below.

This document constitutes a public offer in accordance with applicable law.

1. Definitions

Offer — this document published on the Internet at: https://bimawa.net/offer

Acceptance — full and unconditional acceptance of the terms of this Offer by performing the actions specified in Section 3

Services — software development services, including:

  • Mobile application development (iOS, Android)
  • Web application and service development
  • Server-side application and API development
  • Technical consulting
  • Technical support and maintenance of developed software

Software — the result of Services rendered in the form of mobile applications, web applications, services, software modules, and other software products

2. Subject of the Offer

2.1. The Contractor undertakes to provide the Client with software development Services in accordance with the agreed technical specifications, and the Client undertakes to accept and pay for the Services rendered.

2.2. The specific scope, volume, timeline, and cost of Services shall be determined in the Technical Specification and/or Service Order, which shall be agreed upon by the parties before work commences.

3. Acceptance Procedure

3.1. Acceptance of this Offer is accomplished by the Client performing any of the following actions:

  • Payment of an invoice issued by the Contractor
  • Signing of the Technical Specification or Service Order
  • Written confirmation of agreement with the terms of the Offer (including via email)

3.2. The Agreement shall be deemed concluded upon acceptance of the Offer.

4. Rights and Obligations of the Parties

4.1. The Contractor shall:

  • Provide Services with due quality and within agreed timelines
  • Keep the Client informed of work progress
  • Deliver work results to the Client in the agreed format
  • Maintain confidentiality of information received from the Client
  • Rectify identified defects within the warranty period

4.2. The Contractor is entitled to:

  • Engage third parties to perform work without prior approval from the Client
  • Suspend Services in case of payment delays by the Client
  • Terminate the Agreement in case of material breach by the Client

4.3. The Client shall:

  • Provide the Contractor with necessary information and materials
  • Timely approve Technical Specifications and interim deliverables
  • Pay for Services in accordance with agreed terms
  • Accept work results within established timeframes

4.4. The Client is entitled to:

  • Receive information about work progress
  • Request changes to the Technical Specification by agreement with the Contractor
  • Cancel Services with payment for work actually performed

5. Pricing and Payment Terms

5.1. The cost of Services shall be specified in the Service Order or invoice.

5.2. Payment shall be made by bank transfer to the Contractor's account.

5.3. Payment schedule:

  • 50% advance payment before work commences
  • Final payment within 5 (five) business days after signing the Acceptance Certificate

5.4. The parties may agree on alternative payment terms in the Service Order.

6. Service Delivery Timeline

6.1. Service delivery timelines shall be specified in the Technical Specification or Service Order.

6.2. Timelines may be modified by mutual agreement when changes are made to the Technical Specification.

6.3. The Contractor shall not be liable for delays caused by the Client's actions or inaction.

7. Acceptance Procedure

7.1. Upon completion of work, the Contractor shall provide the Client with work results and an Acceptance Certificate.

7.2. The Client shall review the work results and sign the Certificate or provide a reasoned rejection within 5 (five) business days.

7.3. If no response is received from the Client within the specified period, the work shall be deemed accepted without objections.

7.4. Identified defects shall be documented in writing and rectified by the Contractor within agreed timeframes.

8. Intellectual Property

8.1. Exclusive rights to the developed Software shall transfer to the Client upon full payment for Services.

8.2. Until full payment is received, exclusive rights shall remain with the Contractor.

8.3. The Contractor retains the right to use general solutions, algorithms, and developments in other projects unless otherwise agreed by the parties.

8.4. The Contractor is entitled to reference the Software development in their portfolio unless otherwise agreed by the parties.

9. Confidentiality

9.1. The parties undertake not to disclose confidential information obtained during cooperation.

9.2. The following shall be considered confidential:

  • Technical Specifications and documentation
  • Source code of the Software being developed
  • Commercial information of the Client

9.3. Confidentiality obligations shall remain in effect for 3 (three) years after termination of the Agreement.

10. Warranties

10.1. The Contractor warrants that the developed Software shall function in accordance with the Technical Specification.

10.2. The warranty period is 30 (thirty) calendar days from the date of signing the Acceptance Certificate.

10.3. During the warranty period, the Contractor shall rectify identified errors and defects arising from the Contractor's fault at no additional cost.

10.4. The warranty does not cover:

  • Defects caused by the Client or third parties
  • Defects caused by changes in the environment or third-party services
  • Functionality not specified in the Technical Specification

11. Liability

11.1. For payment delays, the Client shall pay a penalty of 0.1% of the outstanding amount for each day of delay.

11.2. The Contractor's total liability shall be limited to the amount actually received for the relevant phase of work.

11.3. The Contractor shall not be liable for indirect damages, lost profits, or data loss.

11.4. The parties shall be released from liability in case of force majeure.

12. Term and Termination

12.1. The Agreement shall enter into force upon acceptance of the Offer and remain in effect until full performance of obligations by the parties.

12.2. Either party may terminate the Agreement by providing 14 (fourteen) calendar days' written notice.

12.3. If the Agreement is terminated at the Client's initiative, payment shall be made for work actually performed.

12.4. If the Agreement is terminated at the Contractor's initiative, any unearned advance payment shall be refunded to the Client.

13. Dispute Resolution

13.1. Disputes shall be resolved through negotiation.

13.2. If agreement cannot be reached, the dispute shall be submitted to the court at the Contractor's location in accordance with applicable law.

14. Miscellaneous

14.1. The Contractor reserves the right to unilaterally amend this Offer. Amendments shall take effect upon publication of the new version.

14.2. Amendments shall not apply to Agreements already concluded.

14.3. In all matters not covered by this Offer, the parties shall be governed by applicable law.

15. Contractor Details

IP Bunkov Maksim Vladislavovich

This Offer is an official proposal of the Contractor and remains valid until withdrawn.